Claims involving disruption are commonly accepted to be the most difficult to quantify. Disruptions that occur during a working day can lead to productivity loss which, in turn, can lead to time and cost overruns. The solution proposed in this book integrates cost and time in order to develop a site labour productivity measurement system whereby claims involving disruption can be objectively and automatically quantified.

Delay and disruption often impacts entire projects and is prevalent throughout the entire construction and engineering industries - no project or construction professional is immune to the effects. This book is aimed at any construction professional anywhere in the world who is involved in preparing, assessing, managing and/or deciding issues concerning the assessment of additional time to complete the work, and also additional payment for delay and/or disruption to the progress of a construction or engineering project. Delay and disruption is endemic in the construction industry and leads to time and cost overruns. It is therefore essential that delays and/or disruptions are identified early so that corrective action can be taken. However, when delay and/or disruption actually occurs, the issue of quantifying the period of any delay, the effects of disruption, and the quantification of the resulting loss during, and especially at the end, of a project is complicated.

Delay and disruption in the course of construction impacts upon building projects of any scale. Now in its 5th edition Delay and Disruption in Construction Contracts continues to be the pre-eminent guide to these often complex and potentially costly issues and has been cited by the judiciary as a leading textbook in court decisions worldwide, see, for example, Mirant v Ove Arup [2007] EWHC 918 (TCC) at [122] to [135] per the late His Honour Judge Toulmin CMG QC. Whilst covering the manner in which delay and disruption should be considered at each stage of a construction project, from inception to completion and beyond, this book includes: An international team of specialist advisory editors, namely Francis Barber (insurance), Steve Briggs (time), Wolfgang Breyer (civil law), Joe Castellano (North America), David-John Gibbs (BIM), Wendy MacLaughlin (Pacific Rim), Chris Miers (dispute boards), Rob Palles-Clark (money), and Keith Pickavance Comparative analysis of the law in this field in Australia, Canada, England and Wales, Hong Kong, Ireland, New Zealand, the United States and in civil law jurisdictions Commentary upon, and comparison of, standard forms from Australia, Ireland, New Zealand, the United Kingdom, USA and elsewhere, including two major new forms New chapters on adjudication, dispute boards and the civil law dynamic Extensive coverage of Building Information Modelling New appendices on the SCL Protocol (Julian Bailey) and the choice of delay analysis methodologies (Nuhu Braimah) Updated case law (to December 2014), linked directly to the principles explained in the text, with over 100 helpful "Illustrations" Bespoke diagrams, which are available for digital download and aid explanation of multi-faceted issues This book addresses delay and disruption in a manner which is practical, useful and academically rigorous. As such, it remains an essential reference for any lawyer, dispute resolver, project manager, architect, engineer, contractor, or academic involved in the construction industry.

The most significant unanticipated costs on many construction projects are the financial impacts associated with delay and disruption to the works. Assessing these, and establishing a causal link from each delay event to its effect, contractual liability and the damages experienced as a direct result of each event, can be difficult and complex. This book is a practical guide to the process of delay analysis and includes an in-depth review of the primary methods of delay analysis, together with the assumptions that underlie the precise calculations required in any quantitative delay analysis. The techniques discussed can be used on projects of any size, under all forms of construction contract, both domestic and international. The authors discuss not only delay analysis techniques, but also their appropriateness under given circumstances, demonstrating how combined approaches may be applied where necessary. They also consider problematic issues including ‘who owns the float’, concurrent delay, early completion programmes, and disruption. The book has been brought fully up to date, including references to the latest publications from the CIOB, AACEI and SCL, as well as current case law. Broad in scope, the book discusses the different delay analysis approaches likely to be encountered on national and international projects, and features practical worked examples and case studies demonstrating the techniques commonly used by experienced practitioners. This is an invaluable resource to programmers and schedulers, delay analysts, contractors, architects, engineers and surveyors. It will also be of interest to clients’ professional advisors managing extension of time or delay claims, as well as construction lawyers who require a better understanding of the underlying assumptions on which many quantitative delay analyses are based. Reviews of First Edition "John Keane and Anthony Caletka are pukka analysts in that tricky area of delays, programming and extension of time. I highly recommend their book Delay Analysis in Construction Contracts. Buy the book." (Building Magazine, February 2009) "The book′s stated purpose is to provide a practical guide for those interested in schedule delay analysis. It provides a good in–depth review of the most common delay analysis techniques.... An excellent book, full of practical tips for the reader and very timely in its publication. It is well worth the cost and a good read for anyone involved in schedule delay analysis." (Cost Engineering, February 2009) It achieves in spades its stated aim of being a practical guide for contractors, contract administrators, programmers and delay analysts, as well as construction lawyers who require a better understanding of the underlying assumptions on which many quantitative delay analyses are based. (Construction Law Journal, 2009)

Construction Law and Management explains the state of design information appropriate to a given procurement route, and the need to identify risks and strategies for managing them. This handy desk side reference offers a comprehensive guide to construction law and management and is essential reading for anyone in the construction, architecture and engineering industries.

Filled with practical advice for all aspects of the construction manager's role, this invaluable book fills a need for training in this essential subject, to ensure greater efficiency on site and smoother client-contractor relations. Developed as a handy-reference guide for practitioners and also useful for students, it covers the broad range of responsibilities associated with the role, providing clear guidance and in-depth coverage of the essentials. Topics include financial responsibilities and how to handle them, tender preparation, people management, health and safety, contracts, subcontracting, measurement and quantities, insurance and risk and many more simple and effective methods for turning construction projects into reality.

Standard ANSI/ASCE/CI 67-17 presents 35 guiding principles that can be used on construction projects to assess responsibility for delays and to calculate associated damages.